Jump to content

A9 dualling project

Add links
From Wikipedia, the free encyclopedia
(Redirected from A9 Tomatin to Moy)

A9 dualling project
Dualling work in 2021 between Luncarty and Pass of Birnam, the second section of the scheme.
LocationScotland (Perth to Inverness)
ProposerTransport Scotland
Project websiteTransport Scotland's programme
StatusPartially complete[a]
TypeUpgrade to dual carriageway
Cost estimate£3.7 billion[1][b]
Start date2015
Completion date2035 (initially 2025)

In 2011, Transport Scotland envisioned a plan to upgrade the remaining 90 miles (145 km) of the A9, a trunk road in Scotland, between Perth and Inverness from a single carriageway to a dual carriageway. According to this plan, the road will be widened from one to two lanes per direction (two to four lanes total). It also means there will be an increase in speed for cars and motorcycles from 60 mph to 70 mph (97 km/h to 113 km/h).

A dual carriageway allows drivers to overtake safely, as they do not have to meet oncoming traffic; and the crash barriers on the central reservation will greatly reduce the number of head-on collisions. As most of the A9 is currently a single carriageway, drivers may have to overtake heavy goods vehicles (HGVs) and other slow-moving vehicles as they are limited to 50 mph (80 km/h), 10 mph (16 km/h) lower than the speed limit for cars and motorcycles. The project started in September 2015 with a planned completion date of 2025, but has since been deferred to 2035 for various reasons. As of 2024, two sections of the project have been completed—the Kincraig to Dalraddy (near Aviemore) in September 2017, and the Luncarty to Pass of Birnam (near Perth) in August 2021, totalling 11 miles (17 km).

The A9 has been dubbed as Scotland's most dangerous road. In 2022, the number of fatalities rose to its highest level in 20 years.

History

[edit]

Early upgrades

[edit]

The 138 miles (222 km) section between Bridge of Allan and Inverness, via Perth, was substantially rebuilt during the 1970s and 80s, but it follows essentially the same route except where it bypasses towns and villages instead of running through their centres. Between Perth and Inverness, the road has been dubbed Killer A9,[3] because of accidents and fatalities where dual-carriageway sections merge into a single carriageway; the principal cause is that motorists drive at excessive speeds to overtake lines of slower-moving vehicles before the dual carriageway ends. Dangerous overtaking manoeuvres on the long single-carriageway stretches of the road are also common causes of accidents, as are the non-grade separated junctions along the northern sections, where drivers make a right turn across the opposing traffic flow.[4]

One of the sections of dual carriageway built in the late 1970s/ early 1980s; this is the section in the north of Perthshire between Dalnacardoch and Dalnaspidal

The most significant alteration of the A9 route was the realignment of the route north from Inverness, crossing the Moray Firth via the Kessock Bridge, cutting through the Black Isle and back across the Cromarty Firth. This shortened the route by 14 miles (23 km), bypassing Beauly, Muir of Ord and Dingwall. Construction of the Kessock Bridge began in 1976 and it was completed in 1982.[5]

Since 2007, the Scottish Government has given serious consideration to converting the entire Perth-Inverness section to dual carriageway with more grade separated junctions, with the initial estimated cost at £600 million.[6] In late 2008, the Scottish Government's transport plan for the next 20 years was announced. It brought forward planned improvements to the A9 to try to stimulate the economy and protect jobs.[7] This included a commitment to full dualling of the road between Perth and Inverness.[8] Work costing a total of £8.5 million was undertaken at Moy, Carrbridge and Bankfoot. Northbound overtaking lanes were created and the carriageway was reconstructed at both Moy and Carrbridge. Junction improvements were also made at Moy and at the Ballinluig junction, south of Pitlochry.[7][9]

Speed cameras

[edit]
The average speed cameras which became operational on the A9 in Oct 2014

In July 2013, the Scottish Government announced a plan to install average speed cameras on the A9 between Perth and Inverness. This has been undertaken with an aim to reduce accidents and fatalities on the road, and was the second permanent average speed camera scheme in Scotland.[10] Simultaneously, an increased speed limit for heavy goods vehicles from 40 mph (64 km/h) to 50 mph (80 km/h) was introduced to help mitigate driver frustration.[11] Both became operational in October 2014,[12] before HGV speed limit increase would then apply to England and Wales on single carriageways from 40 to 50 mph.[13]

The A9 Safety Group claim that the cameras have had a "positive influence" on road users, with the number of drivers breaking the speed limit by over 10 mph (16 km/h) decreasing by 97%.[14] Improvements to safety include at least 40% reduction in fatalities, and this has been attributed, at least in part, to a reduction in speeding, from 1 in 3 vehicles to just 1 in 15.[15] The average speed cameras may be removed after the A9 dualling project is done.[16]

Road safety statistics

[edit]
See also: Killer A9

It has been reported that the A9 is dubbed the most dangerous road in Scotland.[17] In 2022, despite the installation of average speed cameras, 17 people died on the A9, of whom 13 were on the stretch between Perth and Inverness, where much of the route is single carriageway.[17][18] This has meant that the number of fatalities rose to its highest level in 20 years; between 2019 and 2021, only one death was reported per year.[17][18] However, this plummeted to just four deaths the following year, with half of them on single carriageway sections.[19] As of July 2023, 335 people had been killed on the Perth-to-Inverness stretch of the road since 1979 (an average of 7.6 deaths per year), 59 of which occurred between 2011 and 2022 (an average of 5.4 deaths per year). The "A9 Dual Action Group" was established to bring attention to the statistics. It submitted a petition to the Scottish Parliament in December 2022, calling on the Scottish Government to follow through on its 2011 commitment to convert the remaining 77 miles (124 kilometres)[20] of single carriageway into dual carriageway by 2025.[21] In 2023, the Scottish National Party (SNP) stated that the dualling of the road would not be complete by 2025.[22][23]

The annual average daily traffic (AADT) of the A9 varies between Perth and Inverness from 8500 around Pitlochry, 22,500 around Perth and 37,000 around Inverness.[24]

Construction

[edit]

Announcement

[edit]

In November 2011, the Scottish Government announced that it would upgrade the entire road from Perth to Inverness to dual carriageway.[25] The design contract was split into three lots with Lot 1 (Glengarry to Dalraddy) awarded to a CH2M / Fairhurst joint venture in April 2014.[26] Lot 2 (Pass of Birnam to Glengarry) was awarded to Jacobs in August 2014[27] and Lot 3 was awarded to an Atkins / Mouchel joint venture in December 2014.[28]

Completed sections (2015-2021)

[edit]
Construction works for the (now completed) dual section of the A9 near Alvie

Award of the construction contract for a preliminary section (outwith Lots 1 to 3) of the £3 billion project was awarded in June 2015.[2] Work began on the first 5 miles (8 km) section between Kincraig and Dalraddy (located just south of Aviemore) in September 2015.[29] After a slight delay, this section was opened to traffic two years later on 30 September 2017.[30] It is an isolated stretch of dual carriageway (i.e., this section is not an extension of an existing dual carriageway or something that fills the gap, as was done for the second and third section down below). A 2+1 road section (also known as WS2+1) just of the first section was removed due to the Design Manual for Roads and Bridges (DMRB) CD 109 requirements of having a minimum of 2km of single carriageway in between, as well as an existing bridge in the way.[31]

The second section of the project was the 6-mile (10 km) section between Luncarty and Pass of Birnam, the first section of what was single carriageway just north of Perth. After having the £96 million contract awarded to Balfour Beatty in autumn 2018,[32] construction works began in February 2019.[33] This section was scheduled to finish in spring 2021. However, like the Kincraig to Dalraddy section, it also experienced a slight delay meaning that this section was finished in August 2021 with off-carriageway works to finish by 2022.[34] The first two schemes combined meant that Transport Scotland has converted 11 miles (17 km) of single carriageway to dual carriageway.

Proposed sections

[edit]

Since 2022, no sections of the A9 were either upgraded or under construction. This has also occurred between September 2017 and February 2019 meaning that no major works were also carried out in the whole of 2018.[35] The project will be delivered via a hybrid approach, utilising both 'design and build' (D&B) and 'mutual investment model' (MIM) contracts.[36]

Tomatin to Moy

[edit]

The third section to be upgraded is between Tomatin and Moy, also 6 miles long.[37][38] This is the northernmost section of single carriageway for the scheme. In November 2023, Transport Minister Fiona Hyslop have announced three contractors have been shortlisted for this scheme: John Graham Construction Ltd, Sacyr UK Ltd and Balfour Beatty Civil Engineering Ltd.[37] The £150 million contract was awarded to Balfour Beatty in July 2024 with construction set to last around three years.[39][40] Some preparation works to this section include some trees being cut down and a new railway bridge on the Highland Main Line, which were done in 2021 and 2022, ahead of the main construction work.[41][42] The new railway bridge is also wide enough should the Highland Main Line be doubled in the near future. This stretch is expected to start construction by the end of 2024.[43] Preparatory works on this section began on 21 October 2024, and is expected to begin main construction in spring 2025.[44][45] It's also reported that the section has risen to £308 million from £254 million in July this year and before that, £197 million.[44]

Tay Crossing to Ballinluig

[edit]
The A9 single carriageway (pictured) north of the Jubilee Bridge is scheduled for dualling in 2025

In April 2024, Transport Scotland began procurement for the 5-mile (8 km) section between Tay Crossing (aka, Jubilee Bridge) and Ballinluig project. This involved publishing a Prior Information Notice for a £155 million contract to complete this section.[46] Initial ground survey and borehole samples took place for the section in 2020.[47] In August 2024, three contractors have been shortlisted for this scheme: Balfour Beatty Civil Engineering Ltd, Wills Bros Civil Engineering Ltd and John Graham Construction Ltd.[48] The contract is expected to be awarded in summer 2025.[48]

Table

[edit]

If only the year is shown, it means that construction should start or finish by the end of that year. Unless stated otherwise, the source for the table is:[49]

Section Status Start of work End of work Contract
Kincraig to Dalraddy Complete Sep 2015[29] Sep 2017[30] D&B
Luncarty to Pass of Birnam Complete Feb 2019[33] Aug 2021[50] D&B
Tomatin to Moy Prep works
underway[c] 		Spring 2025[45][d] Spring 2028[45] D&B
Tay Crossing to Ballinluig In preparation 2025 2028 D&B
Pitlochry to Killiecrankie In preparation 2026 2030 D&B
Pass of Birnam to Tay Crossing In preparation 2028 2032 D&B
Dalraddy to Slochd In preparation 2028 2033 MIM
Dalwhinnie to Crubenmore In preparation 2028 2033 MIM
Crubenmore to Kincraig In preparation 2030 2035 MIM
Glen Garry to Dalwhinnie In preparation 2030 2035 MIM
Killiecrankie to Glen Garry In preparation 2030 2035 MIM

Delays

[edit]

The construction project started in September 2015 and was originally scheduled for completion in 2025.[51][52][29] but in February 2023, the Scottish Government reported that the 2025 deadline was "unachievable".[53]A review from the BBC stated that the civil engineers knew that finishing the project by its original deadline of 2025 was going to be impossible for years.[54] In December 2023, Transport Scotland announced that this deadline has been postponed by a decade to late 2035 and announced a new delivery plan.[55] [56] Since 2022, no sections of the A9 were either upgraded or under construction. This has also occurred between September 2017 and February 2019 meaning that no major works were also carried out in the whole of 2018. Former first minister of Scotland Nicola Sturgeon stated that the reason for the delay was because it "faced significant challenges beyond their control, including from Brexit and the Covid[-19] pandemic"[57] and apologised that the 2025 deadline cannot be met. She did not apologise because of the Scottish National Party (SNP) or because the Scottish Government "messed up".[57] Other factors include the Russian invasion of Ukraine.[53] However, these claims were not well received by residents at the northern end of the A9, and it was pointed out that issues such as Brexit, Covid and the War in Ukraine weren't factors when the project started to slow down,[58][59] with former First Minister, Alex Salmond, believing the project became less of a priority after he left the Scottish Government in 2014.[60] The first two sections of the scheme were already delayed by no more than a couple of months. Only 11 out of 90 miles of the A9 were converted to dual carriageway from 2015 to 2023, leaving 79 miles to be dualled. This means that the project is far from completion.[54] According to a 2012 report, Alex Neil, Cabinet Secretary for Infrastructure and Capital Investment, said that the "2025 [deadline] was challenging but achievable"[61]

In March 2024, Fergus Ewing, an SNP politician for the Inverness and Nairn constituency, that is also an MSP (Member of Scottish Parliament) member since 1999, issued a public letter to transport secretary Fiona Hyslop highlighting delays to the project and continuing fatalities on the road.[62] A month prior to this, Ewing was suspended by the SNP for criticizing the party's negligence with particular emphasis on the A9 and A96 dualling delays.[63]

In November 2024, the SNP announced plans to slash the national speed limit on single carriageway roads nationwide from 60mph to 50mph,[64] causing major concern from campaigners that it would further push back dualling of the A9, or lead to the project being cancelled outright, and that a further reduced speed limit would only increase frustration and lead to more accidents.[65]

Criticism

[edit]

Plans to dual the A9 and A96 have been criticised by Patrick Harvie of the Scottish Greens, who has said the plans were incompatible with the Scottish Government's climate initiatives.[66] A study in 2016 found that the dualling project would cost more to construct than it would bring in, including wider economic benefits.[67] The Scottish Government was criticised by the Highland Council for stalling the project.[17] However, in 2024, the Transport Secretary of the Scottish Government stated that Net zero Scotland would still need roads and the government had committed to continuing with the dualling project.[68] The First Minister John Swinney, has feared that the government may de-prioritise the project after the finance secretary warned about not being able to afford its capital commitments.[69]

The A9 runs through the site of the Battle of Killiecrankie. Expanding the road here will destroy some of the battleground. Transport Scotland say dualling the road will have "some impact" on the site.[70]

Notes

[edit]
  1. ^ Only two sections were complete, first being Kincraig to Dalraddy in September 2017, and Luncarty to Pass of Birnam in August 2021, totalling 11 miles (17 km). This leaves another 79 miles (126 km) of single carriageway left to be upgraded. Prep works started on the 6-mi section in Oct 2024 between Tomatin and Moy
  2. ^ up from £3 billion in 2015.[2]
  3. ^ from 21 October 2024
  4. ^ Although preparatory works started on 21 October 2024, main works is expected to begin in spring 2025

References

[edit]
  1. ^ "A9 Dualling Perth to Inverness". Archived from the original on 29 June 2023. Retrieved 15 August 2023.
  2. ^ a b "Major Milestone As A9 Dualling Construction Set To Get Underway | Transport Scotland". www.transportscotland.gov.uk. Archived from the original on 25 November 2015. Retrieved 25 November 2015.
  3. ^ Maciver, Iain (19 July 2023). "Iain Maciver: Killer A9 should keep Scotland's politicians awake at night". Press and Journal. Retrieved 24 January 2024.
  4. ^ Duffy, Judith (25 March 2012). "Scotland's most dangerous roads". Herald Scotland. Retrieved 11 August 2015.
  5. ^ Brocklehurst, Steven (6 March 2014). "Life and death on the A9". BBC News (Scotland - Highlands & Islands). Archived from the original on 21 June 2015. Retrieved 13 August 2015.
  6. ^ "Full A9 upgrade 'to bring extra £300m into economy'". Inverness Courier. 2 November 2007. Archived from the original on 31 January 2016. Retrieved 11 November 2015.
  7. ^ a b "A9 upgrades brought forward in bid to boost economy". Inverness Courier. 5 December 2008. Archived from the original on 31 January 2016. Retrieved 11 November 2015.
  8. ^ Veitch, Kenneth; Fenton, Alexander (2009). Scottish Life and Society. Edinburgh: Donald. p. 464. ISBN 978-1-904607-88-5.
  9. ^ "The toll road: The dangers of driving the A9". The Scotsman. 21 November 2010. Archived from the original on 26 January 2016. Retrieved 11 November 2015.
  10. ^ "Average speed cameras for A9 from Dunblane to Inverness". BBC News (Scotland - Highlands & Islands). 26 July 2013. Archived from the original on 9 November 2018. Retrieved 11 August 2015.
  11. ^ "HGV speed limits in the UK". Archived from the original on 13 May 2024. Retrieved 23 June 2024.
  12. ^ https://www.transport.gov.scot/transport-network/roads/road-safety/
  13. ^ "HGV speed limits in the UK". Archived from the original on 13 May 2024. Retrieved 23 June 2024.
  14. ^ "A9 average speed cameras 'have reduced speeding'". BBC News. 26 January 2015. Archived from the original on 29 September 2015. Retrieved 10 September 2015.
  15. ^ "Comprehensive A9 performance data published". Scottish Government. 20 April 2018. Archived from the original on 9 October 2018. Retrieved 8 October 2018.
  16. ^ "FAQs". A9ROAD.INFO. A9 Safety Group (a multi-agency group set up by Transport Scotland). Retrieved 17 July 2024. Between Perth and Inverness, it is likely that the average speed cameras would be removed after the dualling of a particular section is complete. Judgements on this will be made as circumstances require.
  17. ^ a b c d "Where are Scotland's deadliest roads". The Herald. 30 March 2023. Archived from the original on 10 September 2024. Retrieved 10 September 2024.
  18. ^ a b "Crash deaths on notorious section of the A9 reach 20-year high". BBC News. 5 December 2022. Archived from the original on 10 September 2024. Retrieved 10 September 2024.
  19. ^ "A9 incidents, accidents and fatalities between January 2020 - 2024: FOI release". www.gov.scot. Scottish Government. Archived from the original on 16 September 2024. Retrieved 16 September 2024. This FOI (freedom of information) request was posted on 14 May 2024, responded 5 June 2024 before being published on 1 July 2024. Data for 2023 is provisional as of time of posting.
  20. ^ "Crash deaths on notorious section of the A9 reach 20-year high". 5 December 2022. Retrieved 24 January 2024.
  21. ^ Maciver, Iain (19 July 2023). "Iain Maciver: Killer A9 should keep Scotland's politicians awake at night". Press and Journal. Retrieved 24 January 2024.
  22. ^ Johnson, Simon (9 February 2023). "SNP 'betraying' Highlands by breaking pledge to upgrade 'killer' A9 road". The Telegraph. ISSN 0307-1235. Retrieved 24 January 2024.
  23. ^ "A9 dualling failure laid bare as shovel ready sections ditched". RossShire Journal. 15 June 2023. Archived from the original on 24 January 2024. Retrieved 24 January 2024.
  24. ^ Statistics - Safety/Speed Limits - A9Road Archived 10 September 2024 at the Wayback Machine Retrieved 10 September 2024
  25. ^ "Dualling of Perth to Inverness A9 to finish by 2025". BBC News. 29 November 2011. Archived from the original on 1 December 2017. Retrieved 11 August 2015.
  26. ^ "First multi-million pound A9 Dualling design contract awarded - Ground investigation work to get underway". Transport Scotland. Archived from the original on 25 November 2015. Retrieved 25 November 2015.
  27. ^ "Another multi-million pound A9 dualling contract awarded". Transport Scotland. Archived from the original on 25 November 2015. Retrieved 25 November 2015.
  28. ^ "Young People Jobs Boost From A9 Dualling Contracts". Transport Scotland. Archived from the original on 25 November 2015. Retrieved 25 November 2015.
  29. ^ a b c "Work begins on dualling A9 from Inverness to Perth". BBC News. 10 September 2015. Archived from the original on 10 September 2015. Retrieved 23 June 2024.
  30. ^ a b "First new stretch of A9 dual carriageway opens". BBC News. 30 September 2017. Archived from the original on 1 October 2017. Retrieved 1 October 2017.
  31. ^ "CD 109 - Highway link design". standardsforhighways.co.uk. Archived from the original on 24 June 2024. Retrieved 24 June 2024.. The information for readers is located at para 6.4
  32. ^ "Transport Scotland set to award A9 Dualling: Luncarty to Pass of Birnam construction contract to Balfour Beatty | Transport Scotland". www.transport.gov.scot. Archived from the original on 9 July 2024. Retrieved 9 July 2024.
  33. ^ a b "A9 dualling Luncarty to Birnam - traffic restrictions and overnight closures". Transport Scotland. 22 January 2019. Retrieved 8 July 2024.
  34. ^ "A9 dualling: Milestone met on Luncarty to Pass of Birnam scheme". Ground Engineering. 4 June 2021. Archived from the original on 4 June 2021. Retrieved 8 July 2024.
  35. ^ "Why is there a row over Scotland's longest road?". BBC News. 9 February 2023.
  36. ^ "Transport Scotland | A9 dualling Perth to Inverness". www.transport.gov.scot. Retrieved 9 September 2024.
  37. ^ a b "Contractors shortlisted for delayed A9 Tomatin to Moy upgrade". BBC News. 28 November 2023. Archived from the original on 23 June 2024. Retrieved 23 June 2024.
  38. ^ "Major progress on design of Pass of Birnam to Tay Crossing section of A9 Dualling programme". Transport Scotland. 20 December 2023. Archived from the original on 17 July 2024. Retrieved 8 July 2024.
  39. ^ "New Tender opportunity launched for A9 Dualling: Tomatin to Moy Project". Transport Scotland. 5 September 2023. Archived from the original on 17 July 2024. Retrieved 8 July 2024.
  40. ^ "Next milestone reached for A9 Dualling Programme". Transport Scotland. 9 July 2024. Archived from the original on 9 July 2024. Retrieved 9 July 2024.
  41. ^ Robertson, Lauren (14 February 2022). "Preparation for A9 dualling between Tomatin and Moy gets under way". Press and Journal (Scotland). Archived from the original on 24 June 2024. Retrieved 23 June 2024.
  42. ^ "Mole cuts through railway embankment at Lynebeg in Scottish Highlands". Network Rail. 31 August 2021. Archived from the original on 23 June 2024. Retrieved 23 June 2024.
  43. ^ "First Minister John Swinney vows to progress the A9 dualling". Strathspey Herald. 4 September 2024.
  44. ^ a b "Cost of upgrading six miles of A9 near Inverness rises to £308m". BBC News. 16 October 2024.
  45. ^ a b c "Works programme confirmed for A9 Dualling: Tomatin to Moy with preparatory works set to start on 21 October | Transport Scotland". www.transport.gov.scot.
  46. ^ "Next milestone for the A9 Dualling delivery plan". Transport Scotland. 16 April 2024. Archived from the original on 8 July 2024. Retrieved 8 July 2024.
  47. ^ Anagnostou, Georgios; Benardos, Andreas; Marinos, Vassilis P. (12 April 2023). Expanding Underground - Knowledge and Passion to Make a Positive Impact on the World. CRC Press. p. 1627. ISBN 978-1-000-95782-2.
  48. ^ a b Full steam ahead on A9 Dualling as contractors shortlisted for next section Archived 15 August 2024 at the Wayback Machine Transport Scotland. 15 August 2024
  49. ^ "Delivery Plan". a9dualling.scot. Retrieved 8 July 2024..
  50. ^ "Luncarty to Pass of Birnam Overview". Archived from the original on 23 June 2024. Retrieved 23 June 2024.
  51. ^ Candlish, June (16 June 2015). "First contract awarded to start dualling of the A9". The Press & Journal. Archived from the original on 25 November 2015. Retrieved 11 August 2015.
  52. ^ "A9 dualling Perth to Inverness". Transport Scotland. Archived from the original on 29 August 2015. Retrieved 11 August 2015.
  53. ^ a b "A9 work will not be completed by 2025 target, minister says". BBC News. 8 February 2023. Archived from the original on 19 September 2024. Retrieved 9 September 2024.
  54. ^ a b "'Years of warning' over A9 dualling timescale". BBC News. 14 June 2023. Retrieved 17 July 2024.
  55. ^ "Delivery plan for remaining A9 dualling projects announced". Retrieved 27 December 2023.
  56. ^ "A9 dualling project delayed by 10 years until 2035". BBC News. 20 December 2023. Archived from the original on 20 August 2024. Retrieved 21 August 2024.
  57. ^ a b "Nicola Sturgeon sorry 2025 A9 dualling target cannot be met". 29 May 2024. Archived from the original on 12 July 2024. Retrieved 12 July 2024.
  58. ^ "YOUR VIEWS: A9 dualling delay 'pathetic' – or are problems really down to drivers?". Inverness Courier. 14 February 2023. Retrieved 29 November 2024.
  59. ^ Merson, Adele (29 May 2024). "A9 campaigners react to 'lame excuses' from Nicola Sturgeon over failed dualling promise". Press and Journal. Retrieved 29 November 2024.
  60. ^ Merson, Adele (8 May 2024). "Alex Salmond: A9 dualling delay excuses are 'pathetic'". Press and Journal. Retrieved 29 November 2024.
  61. ^ "Decade of A9 travel chaos". The Herald. 27 June 2012. Retrieved 9 September 2024.
  62. ^ "Multiple A9 deaths sparks furious letter from Fergus Ewing to the transport secretary". Inverness Courier. 28 March 2024. Archived from the original on 8 July 2024. Retrieved 8 July 2024.
  63. ^ "Fergus Ewing to appeal against SNP suspension". BBC News. 1 October 2023. Retrieved 29 November 2024.
  64. ^ Scott, Kevin (27 November 2024). "Scottish Government considers reducing speed limit to 50mph on single-carriageways". STV News. Retrieved 29 November 2024.
  65. ^ "Speed limit on A9 single-carriageway sections could be cut to 50mph". Inverness Courier. 27 November 2024. Retrieved 29 November 2024.
  66. ^ Malik, Paul (12 February 2020). "Scottish Government told continuing to dual the A9 and A96 is at odds with its 'green' budget claims". The Courier. Archived from the original on 23 December 2020. Retrieved 4 February 2021.
  67. ^ "The A9 dualling project – crucial for Scotland?". SPICe Spotlight | Solas air SPICe. 18 February 2020. Archived from the original on 13 March 2020. Retrieved 11 April 2021.
  68. ^ "Net zero Scotland will still need roads, says minister". BBC News. 7 February 2024. Archived from the original on 8 July 2024. Retrieved 8 July 2024.
  69. ^ "Is the A9 dualling at risk due to Scottish Government cuts announced today?". Inverness Courier. 3 September 2024. Retrieved 9 September 2024.
  70. ^ "Campaigners fight plan to dual A9 at Killiecrankie Battlefield". BBC News. 13 January 2020. Archived from the original on 22 January 2020. Retrieved 27 February 2021.
[edit]
Wikimedia Commons has media related to A9 dualling works.

Official

[edit]

Further reading

[edit]
Retrieved from "https://wiki.riteme.site/w/index.php?title=A9_dualling_project&oldid=1260124090#Proposed_sections"